1. ) S.K. Capital Sdn Bhd 2. ) High Tops Fashion Sdn Bhd 3. ) MLK Furniture Trading Sdn Bhd 4. ) Yap Seat Heng 5. ) Low Choon Tow v 1. ) JABATAN PERKHIDMATAN PEMBETUNGAN 2. ) MMC Pembetungan Langat Sdn Bhd PIHAK KETIGA Lonpac Insurance Berhad

ba-23ncvc-1-01-2021 High Court (Mahkamah Tinggi) 27 November 2025 • BA-23NCvC-1-01/2021

Catchwords

1. It is a matter of common experience that public utility construction works often cause inconvenience to the general public, whether by way of traffic diversions, congestion, or other disruptions. Such inconveniences are frequently compounded where the works are prolonged or delayed. 2. In the present case, the Plaintiffs have instituted proceedings against the Defendants, alleging that construction activities carried out along the road adjacent to their shop lots caused undue interference with their business operations. They claim that the disruption resulting from the works led to damage to their properties, a loss of tenants and, consequently, financial losses. The Plaintiffs seek reliefs on the basis of nuisance and economic harm allegedly sustained due to the Defendants’ conduct. 3. It falls upon this Court to make a determination as to whether the Plaintiffs are entitled to reliefs sought based on the evidence before the court and on established legal principles.

Judges (1)

Choong Yeow Choy Delivered

Parties (8)

High Tops Fashion Sdn Bhd Plaintiff JABATAN PERKHIDMATAN PEMBETUNGAN Defendant Lonpac Insurance Berhad Third Party MLK Furniture Trading Sdn Bhd Plaintiff MMC Pembetungan Langat Sdn Bhd Defendant S.K. Capital Sdn Bhd Plaintiff Low Choon Tow Plaintiff Yap Seat Heng Plaintiff

Case Significance

1. ) S.K. Capital Sdn Bhd 2. ) High Tops Fashion Sdn Bhd 3. ) MLK Furniture T... is a High Court (Mahkamah Tinggi) decision dated November 27, 2025 (citation: ba-23ncvc-1-01-2021). The case was decided by Choong Yeow Choy.

What was the outcome of 1. ) S.K. Capital Sdn Bhd 2. ) High Tops Fashion Sdn Bhd 3. ) MLK Furniture T...?

1. ) S.K. Capital Sdn Bhd 2. ) High Tops Fashion Sdn Bhd 3. ) MLK Furniture T... is a High Court decision dated November 27, 2025. The case was heard by Choong Yeow Choy. See the full judgment for details.

Judgment

Read the full judgment on the official Malaysia Courts portal.

Read on eJudgment

Source: eJudgment (ba-23ncvc-1-01-2021)