DELICATE BUILDERS SDN. BHD. v INTIGA SDN. BHD.

wa-12bc-11-09-2023 High Court (Mahkamah Tinggi) 21 April 2025 • WA-12BC-11-09/2023 • 33 min read

24 cases cited (0 SG, 24 foreign)

Catchwords

Whether the delay to the completion of the Project is caused by the defendant - Whether the plaintiff is entitled to back charge the sum of RM131,440.00 on the defendant for the appointment of NYC - Whether the plaintiff is entitled to back charge the sum of RM204,526.98 for scaffolding - Whether the plaintiff is entitled to back charge the sum of RM96,968.80 to the defendant for overtime for Stone Installer - Whether the Defendant is entitled to the sum of RM360,691.17 being the balance amount for work done for the Project

Judges (1)

Aliza binti Sulaiman Delivered

Counsel (6)

Andrew Davis & Co. Firm Ming, Yee & Co. Firm Andrew Davis Counsel Respondent Anne Raj Counsel Respondent Eric Liaw Ming Kok Counsel Appellant Jerome Lee Hui Ming Counsel Appellant

Parties (2)

DELICATE BUILDERS Sdn Bhd Appellant INTIGA Sdn Bhd Respondent

Case Significance

DELICATE BUILDERS SDN. BHD. v INTIGA SDN. BHD. is a High Court (Mahkamah Tinggi) decision dated April 21, 2025 (citation: wa-12bc-11-09-2023). The case was decided by Aliza binti Sulaiman.

What was the outcome of DELICATE BUILDERS SDN. BHD. v INTIGA SDN. BHD.?

DELICATE BUILDERS SDN. BHD. v INTIGA SDN. BHD. is a High Court decision dated April 21, 2025. The case was heard by Aliza binti Sulaiman. See the full judgment for details.

Statutes Cited

Courts of Judicature Act 1964

s 29

Cases Cited (24)

UK (1)

[1981] 2 All ER 513

MY (23)

[1970] 2 MLJ 246 [1984] 2 MLJ 165 [2003] 2 CLJ 19 [2003] 2 MLJ 97 [2004] 4 CLJ 309 [2005] 2 MLJ 1 [2008] 2 CLJ 284 [2008] 2 MLJ 87 [2009] 6 CLJ 626 [2009] 6 MLJ 1 [2010] 3 CLJ 377 [2010] 3 MLJ 509 [2011] 6 MLJ 464 [2012] 4 MLJ 149 [2012] 6 MLJ 1 [2013] 4 MLJ 693 [2015] 2 MLJ 441 [2016] 2 MLJ 428 [2017] 5 CLJ 58 [2017] MLJU 1734 [2020] 12 MLJ 67 [2024] MLJU 2399 [2025] AMEJ 1247

Judgment

Read the full judgment on the official Malaysia Courts portal.

Read on eJudgment

Source: eJudgment (wa-12bc-11-09-2023)