SEIE ENGINEERING SDN BHD v Kerajaan Malaysia

wa-21c-5-08-2022 High Court (Mahkamah Tinggi) 27 April 2025 • WA-21C-5-08/2022 • 46 min read

3 cases cited (0 SG, 3 foreign)

Catchwords

Whether the Plaintiff or Defendant who makes actual decision on the appointment and termination of NSC - Whether the Plaintiff or Defendant is culpable for the delay(s) in the Project, inter alia, the delays caused by – (i) NSC; (ii) design defects; and (iii) issuance of CMGD - Whether the Defendant had wrongly issued the CNC - Whether the CPC dated 10.10.2019 was issued late to the Plaintiff in view that Notice of Completion of Practical Works was given on 7.6.2019 - Whether the Defendant had wrongly imposed LAD and back-charges on the Plaintiff - Whether the Plaintiff is entitled to its claims in this proceeding

Judges (1)

Aliza binti Sulaiman Delivered

Counsel (7)

Attorney General's Chambers Firm C H Tay & Partners Firm Anisah Normah Counsel Defendant Husniyyah Hanapi Counsel Defendant James Ding Counsel Plaintiff Maswirani Mahmud Counsel Defendant Woo Xiao Thong Counsel Plaintiff

Parties (2)

Kerajaan Malaysia Defendant SEIE ENGINEERING Sdn Bhd Plaintiff

Case Significance

SEIE ENGINEERING SDN BHD v Kerajaan Malaysia is a High Court (Mahkamah Tinggi) decision dated April 27, 2025 (citation: wa-21c-5-08-2022). The case was decided by Aliza binti Sulaiman.

What was the outcome of SEIE ENGINEERING SDN BHD v Kerajaan Malaysia?

SEIE ENGINEERING SDN BHD v Kerajaan Malaysia is a High Court decision dated April 27, 2025. The case was heard by Aliza binti Sulaiman. See the full judgment for details.

Statutes Cited

Rules of Court 2012

Cases Cited (3)

MY (3)

[2016] 1 MLJ 507 [2023] 2 MLJ 153 [2023] MLJU 601

Judgment

Read the full judgment on the official Malaysia Courts portal.

Read on eJudgment

Source: eJudgment (wa-21c-5-08-2022)